Terms & Conditions

Terms & Conditions

1.0: In these terms and conditions (which are referred to in this document as “these terms”), the “Customer” means the customer for whom the works are to be carried out by Rehoboth PCP, and the “RPCP” means Rehoboth plumbing, carpentry & property maintenance or, wherever the case may be, a franchisee, sub-contractor or representative of the company carrying out business pursuant to a Franchise/Subcontract Agreement entered into with the company.

“Contract” means the agreement between the Customer and the RPCP to carry out the works of which these terms form a part and (where these terms are a schedule to a signed agreement between the Customer and the RPCP (“the Agreement”)) the Agreement, “Works” means the works described in the RPCP estimate or any other document or email issued by the company, as may be varied by agreement in writing, Email or text message between the parties.

For the purposes of these terms, “in writing” includes by email and any document which is set out in a hand held device and any signature on a hand held screen shall be treated as in writing.

Acceptance Of Works

2.0: The RPCP reserves the right to refuse or decline any work at its own discretion. Where the RPCP agrees to undertake works for the customer, this will be done so by authorised representatives of the RPCP only.

Hourly Work Rate

3.0: Any hourly rate advised to the customer by the RPCP will exclude the supply of any parts required. The RPCP will provide an invoice with the final price for the works carried out for the customer which will include the labour and any equipment or parts supplied.

3.1: All charges payable will only be for work carried out (as described above).

3.2: All charges are subject to price at the prevailing rate.

Estimates And Fixed Price Work

4.0: Any estimate supplied by the RPCP is subject to withdrawal at any time before receipt of an unqualified acceptance from the customer, and shall be deemed withdrawn unless it has been accepted within 28 days from its date.

4.1: Unless otherwise specified, all estimates provided are done on an ‘as is’ basis, and are not a fixed price quotation or firm price. The estimate will set out the likely minimum costs involved based on a visual inspection by the company and/or details supplied by the customer. The final price will be calculated based on the original estimate and in accordance with the companies standard rate card applicable at the time of works being carried out, and may be increased above the estimated price.

In addition, the RPCP reserves the right to increase the price prior to any works being carried out, equivalent to the increase of cost to the company including additional materials, labour, equipment hire and transport since the date of the provided estimate (either done so in writing, email or orally), unless the final price exceeds the estimated price by more than 10%, by which the customer may cancel the contract provided it does so prior to any works commencing (including the order of materials or equipment hired).

4.2: Any estimate provided by the RPCP may be revised in the following circumstances:

4.2a: If after the submission of the estimate by the RPCP, the customer instructs the RPCP (whether in written or orally) to provide additional works or services not referenced or detailed within the estimate.

4.2b: If following the submission of the estimate by the RPCP, there is an increase in the cost of materials to be supplied

4.2c: If following the submission of the estimate by the RPCP, it is discovered further works and services need to be carried out which had not been anticipated.

4.2d: If following submission of the estimate or works carried out, it is discovered that there was a manifest error when the estimate was prepared.

4.3: The RPCP reserves the right to make a charge for the collection of materials, parts and equipment from any supplier, except for works where an estimate has been provided beforehand. If the collection of said materials takes part whilst the RPCP is on site, the time taken for this will be treated as part of the works, and charged at the applicable rate. If any materials are ordered for subsequent collection and delivery, a charge may be made by the RPCP of £55

4.4: The RPCP will not be under any obligation to provide an estimate to the customer. The company will only be bound to estimates provided in writing to the customer, which have also been signed by an authorised representative of the RPCP. The RPCP will not be bound to any estimates provided orally.

4.5: The customer will reimburse the RPCP for any and all expenses incurred (including labour, materials and equipment hire) upon acceptance of an estimate which is subsequently cancelled by the customer.

Prices And Payment

:Any prices or rates advised are subject to VAT at the prevailing rate.

5.1: All invoices are due for payment immediately upon completion of works / delivery to the customer.

5.2: All appointments made for works to be carried out (including fixed price works and estimates) with the company are done so with payment due immediately upon completion / delivery of invoice.

5.3: Where prior written agreement has been arranged for Account Customers with the company, full payment is due within 7 days of the completion of works and delivery of invoice.

5.4: Where any services or works provided by the company is subject to snagging, the customer agrees to make payment of 95% of the total invoice amount immediately following completion of works. The customer must then provide the company access without delay to allow the snagging to be finalised and completed. Payment for the remaining 5% balance will be due following completion of the snagging by the company, or within 7 days of the invoice date should access not be made available – whichever is sooner.

5.5: Where the customer is represented by a third party person(s) or agent(s) (such as a managing agent, landlord, tenant or other occupier, friend, family, contractor or other representative), in the event of non-payment by the customer, the third party will be responsible for full payment unless the company has agreed otherwise in writing prior to any works commencing.

5.6: For any late payments whether in part or in full of an invoice to the RPCP, will be subject to the daily interest rate of 3% over the base rate, until the payment in full is received by the company.

5.7: The company will be under no obligation to provide or issue any guarantees, or other similar documents to the customer for works, unless payment has been made and received in full.

Illustration And Description Of Works

6.0: Any illustrations, descriptions, imagery either displayed on the company’s website, in marketing materials (both offline and online), catalogues, price lists or other are intended merely to present a general idea of works and services provided by the company. No part of these shall form part of any contract.

Inspection, Delivery And Completion Of Works

7.0: The RPCP will advise the customer of the date and time for works to be carried out. The RPCP will always endeavour to ensure they maintain this schedule and that their operatives attend at the agreed time. However, the RPCP accepts no liability in respect of late/non-attendance at any site, or for the late/non delivery of any equipment or materials. All times provided by the company are estimates only.

Indemnity

8.0: The customer shall indemnify the RPCP against any and all actions, claims, demands, suits, losses, costs, expenses and charges which the RPCP may suffer or incur in connection with a claim by a third party, resulting from a breach of the customers obligations, undertakings and representations and warranties in connection with this contract.

Limitation Of Liability

9.0: The Rehoboth PCP liability shall be limited to:

9.0a: the repair or making good of any defect pursuant to its undertaking in paragraph 10 below, and subject to paragraph 7.1 above.

9.0b: liability for personal injury or death resulting from negligence in the course of carrying out the companies duties

9.0c: the reasonable costs of repair or reinstatement of damage or any loss to the customers property, should this result from the negligence of the RPCP or its employees, agents, franchisees or sub-contractors, and the customer incurs such costs.

9.0d: The RPCP will not hold any responsibility for any damage suffered to a part of any property where the damage is in whole or in part a consequence of a defect or weakness in that part of the property.

9.0e: The RPCP will not hold responsibility or liability for damage caused whilst investigating and repairing any plumbing, gas or drainage work, including blockages. This includes but not limited to; the removal of bathroom suites, panels or furniture, tiles and tiling, floor coverings (carpet, rugs, laminate, wood, tiles etc), internal and external walls where pipework is/has to be routed and other damages as a result.

9.0f: If damage to plaster and brickwork is caused it will be the customer’s responsibility to make good. We cannot accept responsibility for any damage to wallpaper, paintwork, tiles, carpet, furniture etc. Any silicone work does not carry any guarantee.

9.0g: It is the responsibility of the customer to protect items of furniture, furnishings, fixtures and fittings. We will make reasonable efforts not to cause damage. It is suggested that the customer remove items that is considered to be a problem. If items remain within the working area, it is the responsibility of the customer to cover such items.

Defects

9.0h: The Client shall indemnify The Company against all claims, damages and costs arising out of the execution of the works unless such claims, damages and costs can be shown to be due to the negligence of The Company. It shall be a condition precedent to the consideration of any claim that The Company has been negligent, that written notice of the alleged act of negligence be given to The Company within seven days of such an act having occurred.

The Client is responsible for gaining ‘Party Wall’ agreements (details of ‘Party Wall’ agreements available on request). The Company shall not be liable for any damage or nuisance caused to neighbour’s property during the normal execution of the contract works. The Client is responsible for notifying, informing and agreeing with the neighbours the manner and sequence of work to be undertaken.

9.0i:  Insurance: The Company is insured for:

: Employer’s Liability

: Public Liability insurance cover up to a limit of £5,000,000

The Client shall ensure that the property is fully insured for normal risks for the duration of the contract.

9.0j:  Arbitration: Should any other disagreement arise in connection with or out of this contract the matters in dispute shall be referred to arbitration in accordance with the Arbitration Act 1950 or any statutory modification or re-enactment thereof for the time being in force.

9.0k:  Invalidation: These conditions have effect in substitution for and to the exclusion of any conditions put forward by The Client.

Should any term in this contract be held to be invalid such invalidation will not affect the validity of the remaining terms.

This contract shall in all respects operate and be construed as an English contract and in conformity with English Law.

10.0: Subject to paragraph 7.1 and the exclusions listed below, the RPCP undertakes to make good and repair any defect in completed work, which appears within six months of the complete date of the same, to the extent that such defect arises from the breach of the RPCP obligations under this contract.

All defects must be notified to the RPCP by the customer in writing within this period, and the company and its insurers must be provided the opportunity to inspect the work and any alleged defect.

This inspection shall only apply to work carried out and completed by the RPCP that has been paid in full by the customer.

Following the inspection and it transpires the alleged defect is not the result of any work or service carried out or provided by the company, the company reserves the right to make a charge to the customer for the inspection visit at its standard rate.

The RPCP reserves the right to not carry out any work where the customer cannot provide sufficient evidence that the work was originally carried out by the RPCP, or where full payment has not been received for said work.

Exclusions are:

10.0a: Any parts or materials supplied by the company will only be provided with the manufacturers or suppliers guarantee, and are not guaranteed by the company

10.0b: Any systems or structures which have not been installed by the company

10.0c: Any defects resulting from the misuse, wilful act or faulty workmanship by the customer or any other third party working for or under the direction of the customer.

10.0d: Any structural defects, such as but not limited to subsidence and its resultant effect.

10.0e: Any damage to drainage systems caused by any outside force or root penetration.

Permits, Licenses, Regulations And Other Consents/Access

11.0: It is the customer’s duty to ensure suitable permission, permits, licenses and all other consents from the owner/landlord/agent/organisation, and/or planning permission if necessary is obtained prior to installation work carried out by the company. The company will not be held responsible for any damage to the property (such as fixings, holes etc.) if this has not been obtained, and in the event of equipment supplied or installed requiring removing or re-positioning, extra charges will be incurred.

The customer shall provide clear access to enable the company to undertake the works, and will make all the necessary arrangements with the proper persons or authorities for any traffic controls and signals required in the connection with carrying out the works.

The customer shall obtain permission for the company to proceed over property belonging to neighbours or third parties if this is necessary. The customer shall indemnify the company in all aspects of claim from neighbouring/third party properties arising out of the presence of the company or its employee’s/representatives.

11.1: The customer will at all times ensure the environment is safe for the company and its employee’s/representatives for the purpose of carrying out the works.

11.2: Where applicable to drainage works and services, the customer shall provide the company, if possible, a plan of the drain layouts. If this is not available, the company reserves the right to make additional charges at the applicable rate if blockages occur in drains not covered or identified by the customer.

11.3: By instructing the RPCP to proceed with any works as agreed, it is thought by the company the customer has sought the necessary permission as set out above. The customer will be liable to the RPCP for all loss and damage whether indirect, direct or consequential which has been suffered by the company as a result of the failure or delay b the customer in performing the obligations as detailed above.

Force Majeure

12.0: The RPCP will use all reasonable efforts to carry out and complete the works on time, but shall not be liable to the customer or any third party if the works prove impossible due to events or circumstances beyond the company’s reasonable control.

Cancellation

13.0: If the customer cancels any contract with the RPCP, without the companies consent, the customer agrees to indemnify the RPCP against any and all loss, damage, claims or actions arising as a result of such cancellation, unless otherwise agreed in writing, and is without prejudice to the RPCP right to payment in accordance with paragraph 5.

Removal Of Waste And Materials

14.0: The RPCP is not responsible for the removal of any waste materials. The customer is responsible for the removal of any/all waste materials resulting from the works carried out by the company.

Frozen Pipes

15.0: The RPCP will not be liable for any fractures found in frozen pipes attended by the company, and cannot guarantee to clear blockages occur within frozen pipes or drainage systems. 

Guarantees

16.0:  Guarantees: The Company will exercise all proper care to ensure that the work is soundly and adequately constructed in the way and for the purpose for which The Client has requested and that when finished it complies with: The Company will rectify any defects in workmanship reported to them within 12 months of the work finishing.(customer supply materials not including this Guarantee when finish work the client has requested details.

Manufacture warranty only company supply appliance or materials 

Any guarantee provided by the RPCP shall be for labour only, in respect of faulty workmanship from 12 months of the date of completion. Any parts, equipment or components supplied by the company will be covered by their respective manufacturer’s warranty.

The companies guarantee will become null and void if the work/appliance completed/supplied by the company is:

– Subject to misuse or negligence

– Repaired, tampered with or modified by anyone other than a company operative/representative. The company accepts no liability for (or guarantee suitability for) materials supplied by the customer or other third parties, and will not accept liability for any damage or faults as a result.

16.1: The company is unable to guarantee any work in respect of blockages in waste and drainage systems.

16.2: The company is unable to guarantee any work which has been undertaken on instruction by the customer, against the companies/operatives advice/recommendations.

16.3: The company will only guarantee work directly undertaken by the company and its employee’s. Any work carried out on behalf of the company by agents or sub-contractors will be guaranteed under their own respective policies.

16.4: The company will not be liable or responsible for any damage or defect arising from work not fully guaranteed or where recommended work has not been carried out.

16.5: The company will not guarantee work where the customer has been notified either verbally or in writing by the company of any related work which requires attention.

16.6: The customer shall be solely liable for any hazardous situation in respect of Gas Safe regulations, or gas warning notice issued, unless otherwise caused by our Gas Safe operative.

16.7: All Gas Safe engineers operate under their own Gas Safe registration, and a such are solely responsible for any gas related work and subsequent liability.

16.8:  Free Issue Services: The Company requires the following to be freely available at all times:

Suitable access to carry out the work

Suitable storage for plant and materials

Supply of electricity and clean water

Use of washing and toilet facilities

Intellectual Property Rights

All content of this website, including graphics and logo’s remain the sole property of the company, and are not to be copied, reproduced or distributed either in part of full, without our prior written consent.

Complaints Procedure

In the unlikely event the customer experiences a problem with the service provided by the RPCP, the customer must put their complaint in writing to the RPCP,37 Teasel avenue, Conniburrow,MK14 7DR at their earliest opportunity. Upon receipt of this complaint, the company will endeavour to resolve the matter within 28 days.

Notice Of Your Right To Cancel

The customer has the right to cancel this contract within seven calendar days starting on the day the notice of right to cancel is issued.

Should you send your cancellation notice in writing via post, it is recommended you retain proof of postage by a certificate of posting, or recorded delivery slip. We advise that all notice of rights to cancel are sent via email.

Notice of cancellation is deemed to be served as soon as it is posted /sent.

Work carried out prior to the expiry of the cancellation period:

By signing a written estimate, you agree work will commence before the seven day cancellation period expires, and should you subsequently cancel in accordance with your rights, you are advised that reasonable payment may be due for any work carried out, including labour at the applicable rate.

Nothing in these terms and conditions is intended to remove your rights regarding the quality of our work, or relating to faulty or misdescribed goods that are supplied as part of our service.